Agreement of Terminal LPG for Engineering, Procurement and Construction (Purchase this doc, Text: 08118887270 (Whatsapp))
1. Contract _________
Page 1 of 44
Owner Contractor
CONTRACT
FOR
LPG Terminal ________ Project
FOR
ENGINEERING, PROCUREMENT AND CONSTRUCTION
(EPC/TURN-KEY)
BETWEEN
PT. ______________________
AND
______________________
CONTRACT No.:
_______________________
__ ____ 20_,_,
_____________, INDONESIA
2. Contract _________
Page 2 of 44
Owner Contractor
TABLE OF CONTENTS
PART I CONTRACT AND INTERPRETATION
Article 1. Definitions
Article 2. Aim of the Contract
Article 3. Non-Waiver
Article 4. Severability
Article 5. Amendment
Article 6. Governing Law and Language
Article 7. Arbitration
Article 8. Laws and Regulations
Article 9. Notices and Communications
Article 10. Effective Date
PART II SUBJECT MATTER OF CONTRACT
Article 11. The Contractor's Scope of Supply
Article 12. The Owner's Scope of Supply
Article 13. Time for Commencement and Completion
PART III CONTRACT PRICE AND PAYMENT
Article 14. Contract Price
Article 15. Payment Of Contract Price
Article 16. Invoicing
Article 17. Bonds
Article 18. Taxes and Duties
PART IV WORK EXECUTION
Article 19. The Contractor's and the Owner's Representatives
Article 20. Packing, Marking and Shipping
Article 21. Progress
Article 22. Testing
3. Contract _________
Page 3 of 44
Owner Contractor
Article 23. Inspection
Article 24. Health, Safety, Security and Environment
Article 25. Standards and Codes
Article 26. Cooperation with Others
Article 27. Responsibility for Work and Property
Article 28. Liability for Accidents and Damage
Article 29. Training
Article 30. Cleaning Up
Article 31. Security Guards and Lighting
Article 32. Mechanical Completion
Article 33. Pre-commissioning and Commissioning
Article 34. Acceptance
Article 35. Confidentiality
PART V. GUARANTEES AND LIABILITIES
Article 36. Guarantees and Liquidated Damages
Article 37. Warranties
Article 38. Patent Indemnity
Article 39. Liability of The Parties
PART VI. RISK DISTRIBUTION
Article 40. Transfer of the Ownership
Article 41. Care of Work
Article 42. Insurance
Article 43. Force Majeure
PART VII. CHANGE IN CONTRACT AGREEMENT
Article 44. Assignment and Subcontracts
Article 45. Variation Order
Article 46. Suspension
Article 47. Termination
4. Contract _________
Page 4 of 44
Owner Contractor
APPENDIX “A” SCOPE OF WORK, MASTER SCHEDULE AND BATTERY LIMIT
APPENDIX “B” TECHNICAL CLARIFICATION
APPENDIX “C” HEALTH, SAFETY, SECURITY AND ENVIRONMENT
APPENDIX “D” TRAINING
5. Contract _________
Page 5 of 44
Owner Contractor
This CONTRACT FOR LPG TERMINAL ............... PROJECT, FOR ENGINEERING,
PROCUREMENT AND CONSTRUCTION (EPC/TURN-KEY) NO. ________ is made and
entered into in ______on the [DATE] (“Contract”), by and between:
PT. ______________________, a limited liability company incorporated under the laws of the
Republic of Indonesia, having its principal address at ....................................................., which
article of association have been amended in accordance with the Indonesian Law No. 40 year
2007 regarding the Limited Liability Company based on deed No. ________ dated ...............
made before Notary ..............., approved by the Minister of Law and Human Rights pursuant
to Decree No. ............... dated ..............., announced in the State Gazzette of the Republic of
Indonesia No. ............... dated ..............., Supplement No. ..............., and the latest article of
association based on deed No. ............... dated ............... made before Notary ...............,
approved by Minister of Law and Human Rights pursuant to Decree No. ...............
dated ..............., announced in the State Gazzette of Republic of Indnoesia No. ...............
dated ..............., Supplement No. ..............., in this matter represented by Reno Pratama
Junizwan in his capacity as the President Director, therefore acting for and on behalf of PT.
______________________ (the “Owner”); and
Consortium [Consortium Name] a consortium of companies established by PT.
______________________ Heavy Industry, a limited liability company incorporated under the
laws of the Republic of Indonesia, having its principal address at ....................................,
which article of association have been amended in accordance with the Indonesian Law No.
40 year 2007 regarding the Limited Liability Company based on deed No. ........
dated ........................ made before Notary ......................, SH, approved by the Minister of Law
and Human Rights pursuant to Decree No. _______________9 dated ..............., announced
in the State Gazzette of the Republic of Indonesia No. 2 dated ..............., Supplement No.
__________, and the latest article of association based on deed No. ..... dated ...............
made before Notary ..............., SH, approved by Minister of Law and Human Rights pursuant
to Decree No. ______________. Tahun ........ dated ........................, announced in the State
Gazzette of Republic of Indonesia No. ....... dated ....................., Supplement No. __________,
PT. [Consortium member], a limited liability company incorporated under the laws of the
Republic of Indonesia, having its principal address at ..............., which article of association
have been amended in accordance with the Indonesian Law No. 40 year 2007 regarding the
Limited Liability Company based on deed No. ............... dated ............... made before
Notary ..............., approved by the Minister of Law and Human Rights pursuant to Decree
No. ............... dated ..............., announced in the State Gazzette of the Republic of Indonesia
No. ............... dated ..............., Supplement No. ..............., and the latest article of association
based on deed No. ............... dated ............... made before Notary ..............., approved by
Minister of Law and Human Rights pursuant to Decree No. ............... dated ...............,
announced in the State Gazzette of Republic of Indnoesia No. ............... dated ...............,
Supplement No. ..............., in this matter represented by ........................ in his capacity as the
[...............] of Consortium, therefore acting for and on behalf of the Consortium [Consortium
Name] (the “Contractor”).
The foregoing may individually be called the “Party” and collectively the “Parties”.
6. Contract _________
Page 6 of 44
Owner Contractor
WITNESSETH:
WHEREAS, the Owner is desirous of engaging a construction company responsible for
engineering, detailed design, fabrication drawings, supply of materials, construction,
installation, testing, commissioning and rectification of works in accordance with this Contract
at Terminal LPG ..............., .................., Indonesia;
WHEREAS, the Contractor is an international E.P.C (Engineering, Procurement and
Construction) with numerous successful experiences in environmental and industrial plant
projects [Note: Need to be confirmed and adjusted if the contractor is changed] and
desires to participate in the Terminal LPG ..............., ..............., Indonesia project;
WHEREAS, the Owner has appointed the Contractor by Letter of Award No. ___________
dated ...................., and the Contractor have accepted the appointment and therefore the
Parties are desirous to implement this Contract.
NOW, THEREFORE, in consideration of the premises and the undertaking of the Parties
herein contained, the Parties hereto agree as follows:
1. DEFINITIONS AND INTERPRETATION
1.1 DEFINITIONS
In the Contract as hereinafter defined, the following words and expressions shall have
the meaning hereby assigned to them except where the context otherwise requires:
(i) "Acceptance" shall mean the acceptance of the Plant in accordance with
Article 34.
(ii) "Article" without a reference to another contract means the Article according
to this Contract.
(iii) “Battery Limit” shall mean the splitting up of the responsibilities between the
Owner (outside of the battery limits) and the Contractor (inside of the battery
limits) as provided in the Appendix “A”.
(iv) "Commissioning" shall mean the operation of the Plant following Pre-
commissioning of the Plant to test that the Plant reach to Performance
Guarantee Figures as stipulated in Appendix “A”.
7. Contract _________
Page 7 of 44
Owner Contractor
(v) “Construction” shall mean performing of all and every civil works,
mechanical works, electrical works, instrumentation works, erection, the
Commissioning and relevant services as defined in the Contract to be done
by the Contractor.
(vi) "Construction Equipment" shall mean all facilities, equipment, machinery,
tools, apparatus, appliances or things of every kind required in/for the
Construction of the Plant to be provided by the Contractor, but does not
include machineries, special tools, spare parts intended to form or forming
part of the Plant, but as necessary with the Equipment Operation Eligibility
Letter (Surat Kelayakan Operasi Peralatan) from Indonesian competent
authority.
(vii) "Contract" shall mean this Contract and all documents listed and attached
herein.
(viii) "Contract Price" shall mean the sum named in the Contract subject to such
additions thereto or deduction there from as mentioned in Article 14 of this
Contract.
(ix) "Contractor" shall mean the Consortium of [Consortium Name] who shall be
liable towards the Owner for the good performance of the Contractor’s
obligations hereunder, and the Contractor’s authorized representatives,
successors, and permitted assigns.
(x) “Contractor’s Representative” shall mean any person nominated by the
Contractor and informed to the Owner in the manner provided in Article 19
hereof to perform the duties delegated by the Contractor.
(xi) "Day(s)" shall mean a calendar day.
(xii) "Drawings" shall mean any drawing and any modifications of such drawings
to be approved in writing by the Owner and such other drawings as may from
time to time to be furnished or approved in writing by the Owner.
(xiii) "Effective Date" shall mean the date that this Contract enters into full force
and effect upon fulfillment of all the conditions stated in Article 10 hereof.
(xiv) “Engineering” shall mean all activities related to basic design, detailed
design, providing technical documents, project management, inspection,
testing, monitoring, reporting, scheduling, programming, controlling.
(xv) “FIDIC” shall mean Federation Internationale des Ingenieurs-Consells
8. Contract _________
Page 8 of 44
Owner Contractor
(International Federation of Consulting Engineers).
(xvi) “Force Majeure" shall have the meaning as defined in Article 43.
(xvii) “Liquidated Damages” shall have the meaning as the Contractor’s
payments of damages to the Owner for the default of his different
responsibilities as per Article 36.
(xviii) “Liquified Petroleum Gas” or “LPG” shall mean mixture of ethane, propane,
butane and pentane plus in liquid form and pressurized.
(xix) “LPG Terminal” shall mean reception facilities, storage and distribution of
LPG and other supporting facilities at Site.
(xx) "Materials" shall mean both Off-Shore and On-Shore materials.
(xxi) "Mechanical Completion" means that the Plant has been completed
mechanically and structurally as provided in Article 32.
(xxii) “MIGAS” shall mean Directorate General of Oil and Gas, Ministry of Energy
and Mineral Resources of Republic Indonesia.
(xxiii) “Mill Certificate” shall mean documentation from a testing facility that
usually shows the chemical makeup and physical strength/properties of
materials required to meet certain ASME (American Society of Mechanical
Engineers) and ASTM (American Society for Testing and Materials)
American Society for Testing and Materials.
(xxiv) "Month(s)" shall mean Gregorian calendar month.
(xxv) "Off-Shore Materials" shall mean any and all equipment, machinery,
special tools for maintenance, apparatus, materials, articles and things of all
kinds to be procured from Japan, Europe, North America and/or Korea
(outside Indonesia) and supplied by the Contractor for incorporation into the
Plant.
(xxvi) "On-Shore Materials" shall mean any and all equipment, machinery,
apparatus, materials, articles and things of all kinds to be procured inside
Indonesia and supplied by the Contractor under the Contract, but does not
include Construction Equipment.
(xxvii) "Owner" shall mean PT. ______________________ who is named as such
in this Contract and includes the legal successors or permitted assigns of
the Owner.
9. Contract _________
Page 9 of 44
Owner Contractor
(xxviii) "Owner’s Representative" shall mean any person appointed by the Owner
in the manner provided in Article 19 hereof to perform the duties delegated by
the Owner.
(xxix) "Party" shall mean individually, the Owner or the Contractor.
(xxx) “Parties” shall mean the Owner and the Contractor collectively.
(xxxi) “Performance Acceptance Certificate or “PAC” shall mean a certificate
to be issued under the Contract by the Owner at the successful completion
of the Commissioning of the Plant.
(xxxii) "Performance Bond" shall mean the bank guarantee from a state owned
bank in Indonesia acceptable to the Owner by the Contractor according to
Article 17 of this Contract for securing the good performance of his
obligation.
(xxxiii) “Performance Guarantee Figures” shall mean the technical performance
guaranteed figures stipulated in Appendix “A”.
(xxxiv) "Plant" shall mean the LPG Terminal capable of storing 10,000 (ten
thousand) ton of LPG including jetty, sub-sea pipe, loading arm, spherical
tank to be constructed and performed on the Site.
(xxxv) “Pre-commissioning” shall mean the functional tests of the equipment, i.e.
the running of single or a series of machines and equipment with electricity,
nitrogen, water, air, product and other process media under operation
temperature and/or pressure as far as possible or necessary.
(xxxvi) "Project Schedule" shall mean the time schedule setting forth the expected
commencement dates and/or completion dates of certain activities required
for engineering, procurement, construction.
(xxxvii) "Site" shall mean the location at which Work shall be performed under the
Contract.
(xxxviii)“SKPP” shall mean Certificate of Eligibility Use of Equipment (Sertifikat
Kelayakan Penggunaan Peralatan) issued by MIGAS.
(xxxix) “SKPI” shall mean Certificate of Eligibility Use of Installation (Sertifikat
Kelayakan Penggunaan Instalasi) issued by MIGAS.
(xl) "Subcontractor" shall mean any supplier, manufacturer, vendor,
10. Contract _________
Page 10 of 44
Owner Contractor
construction firm and service company to whom execution of any part of the
Work, including preparation of any design or supply of any materials, is sub-
contracted directly or indirectly by the Contractor, and includes its legal
successors or permitted assigns.
(xli) "Supply" shall mean the supply of all the Materials, all associated
engineering works and services to be undertaken by the Contractor in
accordance with the provision of the Contract for the completion of the Plant.
(xlii) “Variation Order” shall mean any variation, alteration, addition, omission,
modification and/or amendment to the scope of Works caused by a change
order as per Article 45.
(xliii) “Vendor” means a vendor providing the Supply or a part thereof for the
Contractor.
(xliv) “Warranty Bond” shall mean the bank guarantee from reputable bank
acceptable to the Owner by the Contractor according to Article 17 of this
Contract for securing the Plant’s performance within the Warranty Period.
(xlv) “Warranty Period” shall mean the period of 12 (twelve) Months from the
issuance date of the PAC or 1 (one) month later after the Plant is ready for
Commissioning (whichever comes earlier) which the Contractor is
responsible for defects with respect to the Plant or any part(s) thereof as
provided in Article 37 hereof.
(xlvi) “Work” shall mean all of the Contractor’s obligations under the Contract in
respect of the construction of a complete and operational Plant as specified
in the Contract, including supply of engineering, procurement, construction,
training, Pre-commissioning of the Plant at the Site and the fulfillment of all
obligations with regard to the Commissioning as specified in Article 33.
(xlvii) “Working Days” shall mean Monday to Saturday except Indonesian public
holiday(s), formal working day in calendar calculation.
(xlviii) “Writing” shall mean any manuscript typewritten or printed statement duly
signed by the authorized representatives.
1.2 INTERPRETATION
a. Unless the context otherwise requires, references herein to the plural include
the singular and references to the singular include the plural.
b. All references to Articles are to articles in or to this Contract unless otherwise
11. Contract _________
Page 11 of 44
Owner Contractor
specified herein.
c. Unless the context otherwise requires, the words "herein", "hereof” and
"hereunder" and words of similar import when used in this Contract shall refer
to this Contract as a whole and not to any particular provision of this Contract.
d. References in this Contract to any statute, law, decree, regulation, or other
legal requirement shall be construed as a reference to such statute, law,
decree, regulation or other legal requirement as re-enacted, re-designated,
amended or extended from time to time, except as provided otherwise in this
Contract.
e. References to any document, instrument or agreement shall mean such
document, instrument or agreement as the same may be amended from time
to time in accordance with the terms and conditions thereof.
f. The table of contents and the headings of the several Articles and Schedules
and/or Appendixes of this Contract are intended for convenience only and shall
not in any way affect the meaning or construction of any provision therein.
g. Reference to the words "include" or "including" shall be deemed to be followed
by the words "without limitation" or "but not limited to", whether or not they are
followed by such phrases or words of similar import.
2. AIM OF THE CONTRACT
The object of this Contract is to construct LPG terminal at [..............., ............... in
Indonesia] (Site) with a storage capacity of .......... (...............) ton and its
complementary unit as described and scheduled on Appendix “A”, which includes:
(a) Performance of complete engineering affairs;
(b) Supply of all equipment and materials, with the objective that when erected
properly, will result in an efficiently operable and integrated Plant in accordance
with the Contract;
(c) Performance of complete construction, erection of the Plant, installation,
testing, Commissioning and rectification of defect for the Works;
(d) Pre-commissioning and Commissioning with the Owner’s operator in
accordance with the Contract;
(e) Manual book of standard procedure in operation the LPG Terminal;
12. Contract _________
Page 12 of 44
Owner Contractor
(f) Training of the Owner’s qualified and skilled personnel in operation and
maintenance of the plant both inside and outside of Republic of Indonesia.
3. NON-WAIVER
3.1 Failure by either Party to insist upon strict performance of any terms or conditions of
this Contract, or failure or delay to exercise any rights or remedies provided herein or
by law, or failure to properly notify the other Party in the event of breach, or the review
or failure to review any designs shall not release any Party from any of the warranties
or obligations of the Contract and shall not be deemed a waiver of any right of any
Party to insist upon strict performance hereof or any of its rights or remedies as to
any prior or subsequent default hereunder nor shall any termination or suspension
under the Contract by any Party operate as a waiver of any of the terms hereof.
3.2 Any waiver of a Party's rights, powers or remedies under the Contract must be in
writing, dated and signed by an authorized representative of the Party granting such
waiver and must specify the right and the extent to which it is being waived.
4. SEVERABILITY
4.1 If any provision, in whole or in part of the Contract should be found legally, invalid,
void or unenforceable or in ineffective, the validity of the other provisions of the
Contract shall not be affected thereby. Both Parties shall endeavour to promptly
replace the invalid or ineffective term or provision by valid and effective one which
correspond best to the original economic and general intent of both Parties and what
the Parties intended by such original provision to carry out their purposes.
4.2 Neither Party shall have any liability, obligation or responsibility which is not
specifically referred to in the Contract.
5. AMENDMENT
Any amendment/addendum of this Contract shall be in writing and signed by
authorized representatives of the Parties.
6. GOVERNING LAW AND LANGUAGE
6.1 This Contract and all amendments, modifications, alterations, or supplements
hereto, and all disputes or claims concerning the validity, scope, meaning,
13. Contract _________
Page 13 of 44
Owner Contractor
construction, interpretation, or application of this Contract, any of its provisions, or
the performance thereunder by either Party or both Parties shall be construed and
interpreted in accordance with the laws of the Republic of Indonesia.
6.2 This Contract shall be executed in both Bahasa Indonesia and English language. In
the event of inconsistency between the Indonesian and English language text, the
English text shall prevail.
6.3 This Article shall survive after the termination of the Contract.
7. ARBITRATION
7.1 Any and all dispute or disagreements or claims or controversies between both
Parties arising out of or in connection with the Contract or the performance thereof
shall be amicably settled between both Parties hereto, failing which such dispute
shall be settled by arbitration in accordance with the Rules of Conciliation and
Arbitration of the International Chamber of Commerce, in Singapore (“ICC”) by 3
(three) Arbitrators, one of whom shall be appointed by the Owner, one by the
Contractor and the third one jointly by the Owner and the Contractor.
7.2 If such an appointment by the respective Party has not been communicated as per
the Contract within 30 (thirty) Day(s) after receipt of the request for such selection, or
if the Parties have not reached an agreement within the said 30 (thirty) Day(s) period
upon the appointment of the third Arbitrator, such appointment shall be made by the
ICC in accordance with the said Rules.
7.3 The arbitration shall be conducted in accordance with the then prevailing Rules of
Arbitration (“Rules”) of the ICC under said Rules.
7.4 The decision of the Arbitrators shall have a binding effect upon the Parties, and in
reaching their decision the Arbitrators shall apply the law of the Contract.
7.5 The place of arbitration shall be in Singapore. The award rendered by the arbitration
shall be final and binding upon both Parties, and resort to any Judicial Court or
Tribunal is hereby waived except for the purpose of enforcement of such award.
7.6 The language of the arbitration shall be English.
7.7 This Article shall survive after the termination of the Contract.
8. LAWS AND REGULATIONS
14. Contract _________
Page 14 of 44
Owner Contractor
8.1 The Parties hereof shall respect FIDIC regulations.
8.2 The Contractor shall respect and observe local laws, regulations, decisions and
order and shall obey orders and instructions issued by governmental and local
authorities.
8.3 The Contractor shall also avoid any action, which can be prejudicial to security and
public order.
8.4 The Contractor, its employees, Subcontractors, the Vendors and representatives
shall at all times acquaint themselves in their individual behavior and conduct and
comply with applicable laws, ordinances, statutes, rules or regulations.
8.5 The Contractor shall hold the Owner harmless from and against any and all liabilities,
damages, claims, fines, penalties and expenses of whatever nature suffered by the
Owner arising out of or resulting from the violation of such laws and regulations by
the Contractor and its personnel.
8.6 The Contractor shall act as an independent the Contractor performing the Contract.
The Contract does not create any agency, partnership, joint venture or other joint
relationship between both Parties. Subject to its compliance with the Contract, the
Contractor shall be solely responsible for the manner in which the Work is
performed.
8.7 All employees, representatives, Subcontractors or Vendors engaged by the
Contractor in performing the Contract shall not be deemed to be employees of the
Owner, and nothing contained in the Contract or in any subcontract awarded by the
Contractor shall be construed to create any contractual relationship between any
such employee, representative, Subcontractor or Vendor and the Owner.
9. NOTICES AND COMMUNICATIONS
9.1 All notices required to be served by provisions of this Contract shall be in writing,
either delivered personally or by fax/e-mail communications duly addressed and
confirmed by letter. Notices to be served on both Parties hereto shall be served at or
mailed to the addresses described below or at such other addresses as the recipient
Party may from time to time designate by written notice to the other Party.
9.2 The receiving Party shall promptly confirm the receipt of any notice left at its office by
putting its seal and signature on a copy presented for this purpose.
9.3 Each Party shall notify to the other the names and the signatures of the persons duly
empowered for signing such notices.
15. Contract _________
Page 15 of 44
Owner Contractor
9.4 Any notice sent by airmail post and/or registered mail shall be deemed (in the
absence of evidence of earlier receipt) to have been delivered 7 (seven) Day(s) after
dispatch and in proving the fact of dispatch it shall be sufficient to show that the
envelope containing such notice was properly addressed, stamped and conveyed to
the postal authorities for transmission by air mail, and notices sent by e-mail or by
facsimile transmission shall be deemed to have been received at the time of the
dispatch thereof, answerback received (in the case of telex) or appropriate evidence
of transmission received (in the case of facsimile).
9.5 Either Party to the Contract may change its nominated address by prior written
notice to the other.
9.6 The Contractor shall transmit correspondences and invoices to the Owner at the
following address:
The Owner:
PT. ______________________
....................................................
....................................................
Attention : ....................................................
Tel No. : ....................................................
e-mail. : ....................................................
The Contractor:
______________________.
10. EFFECTIVE DATE
This Contract shall become effective on the date of this Contract is signed.
11. THE CONTRACTOR’S SCOPE OF SUPPLY
11.1 General Obligation of the Contractor
In consideration of the payments by the Owner to the Contractor for the completion
of Works, the Contractor shall be responsible for execute, provide and supply the
Engineering, technical documentation, equipment, consumables, Materials, spare
parts, the Construction, with due care and diligence within the time for completion in
16. Contract _________
Page 16 of 44
Owner Contractor
accordance with this Contract. The specific obligations are defined in the Appendix
“A”.
11.2 Specific Obligation of the Contractor
11.2.1 The Contractor by entering into this Contract shall be deemed to have
satisfied himself as to all conditions and circumstances affecting the Contract
Price, as to the possibility of executing the Works as shown and described in
the Contract, and as to the general circumstances at the Site of the Works,
unless otherwise agreed by the Parties in this Contract.
11.2.2 The Site conditions are in accordance with the information supplied by the
Owner. The Contractor shall be responsible for any misunderstanding or
incorrect information however obtained from other parties, except for the
information given by the Owner.
11.3 The Contractor shall provide utility necessary for the Construction.
11.4 Pre-commissioning and the Commissioning shall be carried out by the Contractor
with the Owner’s support and attended by the representatives of MIGAS and
Pertamina.
11.5 Each item of Materials supplied by the Contractor shall be entirely of proven design
and unused (proved by Mill Certificate and/or Materials testing as required), of good
quality workmanship and shall be free from defects in design, materials,
manufacturing and workmanship suitable for the use intended.
11.6 All Materials supplied by the Contractor shall be delivered on the basis of delivery at
place at Site as per INCOTERMS 2000. The payment of customs duty, Value Added
Tax import, customs clearance and any other charges related with customs
clearance shall be taken care of by the Owner at its cost.
11.7 The Contractor shall be responsible for all inland transportation of On-Shore
Materials within Indonesia.
11.8 The Contractor shall provide drawings, operating and maintenance manuals for all
equipment provided under the Contract.
11.9 The Contractor shall provide 4 (four) sets hardcopy of “As-Built” and 1 (one) set
softcopy for the Work (one set reproducible for drawing) performed hereunder at the
completion of the Work.
11.10 The Contractor shall provide the Owner, in accordance with coordination procedure
of all plans, of all drawings, design specification, progress reports, the Contractor’s
test results and other data prepared by the Contractor, Vendors or the
17. Contract _________
Page 17 of 44
Owner Contractor
Subcontractors, if any, in connection with the Plant, the list of which shall be defined
and agreed between both Parties. The Owner shall retain rights to drawings,
technical requisitions, specifications and other project documents as instruments of
service for this Plant.
11.11 The Contractor shall arrange its shipment in an expeditious and orderly manner
taking into account the schedule of the erection of the Plant. The Owner shall provide
full cooperation with the Contractor and Subcontractor(s) for the successful carry out
of the erection and construction of the Plant.
11.12 The Contractor shall be responsible for the timely performance of all Works in
accordance with the Project Schedule agreed between both Parties, unless for
reasons beyond the control of the Contractor and/or not due to the negligence or
willful misconduct of the Contractor.
11.13 The Contractor shall have the right at his own discretion to select Vendors and the
Subcontractors and shall obtain the Owner’s written approval considering the vendor
list.
11.14 The Contractor agrees that all services required in the performance of the Work
(except those specifically furnished by the Owner under the Contract) shall be
furnished and paid for by the Contractor at its expense and account. Unless
otherwise stated in the Contract, such items of services shall include the
Contractor’s site office, temporary electrical wiring or apparatus, temporary piping,
sanitary, water for Works, valves, pumps and piping accessories, with connection
from process Battery Limits as described in Appendix “A”, supply of first aid, medical
services for its workers, on the project site sheds, huts, shelters, shops, and such
other facilities that may be required during the term of the Contract. The Contractor
shall, at the completion of the Work herein undertaken, remove all such temporary
facilities and services, except such items which have specifically been agreed upon
in writing between the Owner and the Contractor, leaving the premises in clean and
orderly conditions.
11.15 The Contract Price herein agreed to be paid by the Owner to the Contractor shall be
in compensation for the performance and completion of the Work, and not as per
diem compensation for the number of Day(s) which both Parties may estimate as
necessary for the completion of the Work. It is further agreed that the time or times
specified herein shall not be construed to limit and restrict the obligation of the
Contractor to such period, but the Contractor shall proceed with the Work during all
such times as shall be necessary to perform and complete the Work, at no further
expense to the Owner than as herein stated in Article 14 of the Contract, unless
otherwise agreed by both Parties under the Article 45.
11.16 The Contractor shall oblige Subcontractor to obtain all licenses, permits or
authorizations which Subcontractor is required to obtain its own name in accordance
18. Contract _________
Page 18 of 44
Owner Contractor
with the applicable laws or regulations of Indonesia for the performance of Work
under the Contract with the support and assistance of the Owner and the Owner
shall acquire all permits, approvals and/or licenses from all local, state or national
government authorities or public service undertakings which require the Owner to
obtain in its name and which are necessary for the execution of the Works.
11.17 The Contractor shall be responsible for all costs and expenses incurred in
connection with the import and export of Construction Equipment, if require.
11.18 Unless otherwise stated in the Contract, the Contractor shall be responsible to
provide the followings at the Contractor’s cost:
(a) Suitable and proper storage facilities at Site for Plant equipment;
(b) Employment of the local personnel as per the qualification to be laid down by
the Contractor before starting the related work and services of the Plant, in
accordance with the prevailing local laws;
(c) Provision of the necessary services and facilities for the Contractor’s
supervision staffs in accordance with Appendix “A”.
12. THE OWNER’S SCOPE OF SUPPLY
12.1 The Owner shall assign sufficient space at the Site for the Contractor to effectively
execute the Work. The Contractor shall confine its activities within such space or
areas for the execution of the Work, it shall request the Owner for further assignment
of space and areas at the Site and the Owner shall provide such additional space.
12.2 The Owner shall provide utility necessary for the Pre-commissioning and the
Commissioning.
12.3 The Owner shall provide LPG, chemicals, water, electricity, and consumables
necessary for Pre-commissioning and Commissioning according to conditions.
12.4 Unless otherwise stated in the Contract, The Owner shall be responsible to provide
the followings at the Owner’s cost:
(a) To provide the Contractor with all such information and instruction as required
under the Contract, in order to enable the Contractor to execute and complete
the Work;
(b) To obtain all necessary permits, licenses and authorizations to execute this
Contract from Government and/or local authorities. In connection therewith, the
Contractor will perform assistance work to obtain the above permits, licenses
and authorizations as described in Appendix “A”.
19. Contract _________
Page 19 of 44
Owner Contractor
13. TIME FOR COMMENCEMENT AND COMPLETION
13.1 Upon the signing of the Contract and the receipt by the Contractor of the
notification from the Owner’s bank on the readiness of the irrevocable
Stand By Letter of Credit (“SBLC”) to guarantee the fulfillment of payment
obligation by the Owner under this Contract, the Contractor shall forthwith
commence the engineering work.
13.2 Unless for reasons attributable to the Owner and/or the force majeure conditions, the
Contractor shall complete the Works within the period of 20 (twenty) Months (plus 1
(one) month of grace period) commencing from the issuance date of the
Performance Bond.
13.3 If for any reasons not attributable to the Contractor nor within the control of the
Contractor the Project Schedule is interrupted or delayed or there are reasonable
grounds for expecting delay, the Contractor shall promptly advise the Owner, and the
Contractor and the Owner shall promptly meet to discuss remedial action and
whether a change in the Project Schedule is necessary.
13.4 The Contractor’s document and Drawings to get the Owner’s review and approval,
document(s) shall be returned to the Contractor within the 7 (seven) Day(s) after the
Owner’s receipt of the Contractor’s document. If any, documents shall be deemed to
be reviewed and/or approved.
14. CONTRACT PRICE
The Contract Price to be paid by the Owner to the Contractor in consideration of the
Contractor's performance for the Engineering and Supply and the Construction
under the Contract shall be US$...................... (....................................................
United States Dollars) only.
15. PAYMENT OF CONTRACT PRICE
15.1 The payment of the Contract Price shall be made by the Owner to the Contractor
with the following terms:
(a) The amount of 85% (eighty five percent) of the Contract Price shall be paid
from the Owner to the Contractor with the following conditions:
20. Contract _________
Page 20 of 44
Owner Contractor
(i) the Work has achieved 85% (eighty five percent) progress as
evidenced by the monthly progress report already signed by the
Contractor and the Owner;
(ii) any SKPP obtained at the time the 85% (eighty five percent) of the
Work’s progress achieved; and
(iii) all equipments required for the Plant have been delivered to the Site;
(b) The amount of 15% (fifteen percent) of the Contract Price shall be paid from
the Owner to the Contractor after the issuance of the SKPI.
15.2 Both Parties will specify and agree on the measurement of progress of the Work
implementation in the Appendix ”A”.
15.3 During the implementation of the Work, the Contractor will request the approval of
progress to the Owner in accordance with the Appendix “A”.
16. INVOICING
16.1 85% (85% (eighty five percent) of the Contract Price Invoice
For the payment of the 85% (eighty five percent) of the Contract Price, the
Contractor shall submit the following documents to the Owner:
(a) 1 (one) original invoice and 3 (three) copies of the invoice;
(b) 1 (one) set of original bill of lading and/or Airway bill;
(c) 1 (one) original of packing lists;
(d) 1 (one) original of a certificate of origin;
(e) 1 (one) copy of erection all risks insurance certificate.
16.2 15% (fifteen percent) of the Contract Price invoice
For the payment of the remaining 15% (fifteen percent) of the Contract Price, the
Contractor shall submit the following documents to the Owner:
(a) 1 (one) original invoice and 3 (three) copies of the invoice
17. BONDS
17.1 The Contractor shall provide the bonds specified below in favor of the Owner issued
by a state owned bank in Indonesia, in the amount, manner and form specified
below.
17.2 Performance Bond
21. Contract _________
Page 21 of 44
Owner Contractor
Within 5 (five) Working Day(s) after the issuance date of the notification from the
Owners Bank regarding the SBLC, the Contractor shall provide Performance Bond
to the Owner in an amount of US$................. (.......................................... United
States Dollars) only which is validfor 21 (twenty one) Months from the issuance date
of the Performance Bond or will be expired at the issuance of the PAC.
In the event that Project Schedule is extended due to reasons attributable to the
Contractor, the validity of the Performance Bond shall be extended to the extended
period as agreed by the Parties.
The Performance Bond shall be returned and released to the Contractor within 5
(five) Working Day(s) upon the lapse of the abovementioned validity of the
Performance Bond or the issuance date of the PAC.
17.3 Warranty Bond
The Contractor shall provide Warranty Bond to the Owner in amount of
US$................... (........................................... United States Dollars) only which is
valid within the Warranty Period.
18. TAXES AND DUTIES
18.1 The Contract Price stipulated in Article 14 excludes all kinds of taxes, which the
Owner may have to pay in Indonesia.
18.2 Any and all taxes or charges excluding Value Added Tax (Pajak Pertambahan Nilai)
as may be levied in Indonesia with respect to the execution of the Work by the
Contractor under the Contract shall be borne and paid by the Contractor.
18.3 Import Value Added Tax (Pajak Pertambahan Nilai), if any, to be imposed on any
import of the Off-Shore Materials shall be borne and paid by the Owner.
19. THE CONTRACTOR’S AND THE OWNER’S REPRESENTATIVES
19.1 For purposes of coordinating the Work to be performed by the Contractor hereunder,
the Contractor shall nominate its Contractor's Representative.
19.2 Such Contractor’s Representative may also be nominated as project manager or a
nomination of project manager shall be made simultaneously.
22. Contract _________
Page 22 of 44
Owner Contractor
19.3 The Owner may by notice in Writing to the Contractor object to any representative or
person(s) employed by the Contractor in the execution of the Works who shall in the
reasonable opinion of the Owner misconduct himself or be incompetent or
negligent, or commit a serious breach of Site regulations. The Owner shall
substantiate the same whereupon the Contractor shall remove such person from
the Site.
19.4 The Contractor’s Representative shall represent and act for the Contractor at all
times during the currency of the Contract and shall give to the Owner all the
Contractor’s notices, instructions, information and all other communications under
the Contract. All notices, instructions, information and all other communications
given by the Owner under the Contract shall be given to the Contractor’s
Representative, except as herein otherwise provided. The Contractor shall not
revoke the appointment of the Contractor’s Representative without the Owner's prior
written consent, which shall not be unreasonably withheld. If the Owner consents is
not given, the Contractor shall appoint some other person as the Contractor’s
Representative, pursuant to the procedure set out in Article 19.3.
19.5 If any representative or person employed by the Contractor is removed in
accordance with Article 19.3 above the Contractor shall promptly appoint a
replacement according to provisions herein above clauses.
19.6 Upon approval of the Contractor's Representative, the Owner shall advise the
Contractor of the Owner's representative.
20. PACKING, MARKING AND SHIPPING
20.1 The Contractor shall provide the Materials with adequate and seaworthy export
packing suitable for long distance transportation and normal handling during
transportation. The shipping mark of package and cases shall be as follows:
- Contract Number:
- Port of Loading
- Port of Discharge
- Shipper/Exporter
- For Account & Risk of Messrs
- Notify Party
- Gross Weight
- Net Weight
- Package/Case No.
23. Contract _________
Page 23 of 44
Owner Contractor
- Measurement: ________ mm x _________ mm x __________ mm
The Contractor may add such other numbers, words, references, etc. as the
Contractor may require.
20.2 Within 6 (six) Months after the Effective date, the Contractor shall submit to the
Owner a preliminary shipping schedule indicating expected items, value, and time of
shipment.
20.3 The Owner may give its comments to the Contractor within 1 (one) Month after
receipt of such preliminary schedule. A definite shipping schedule shall be agreed
between both Parties and submitted to the Owner based on such preliminary
schedule and the Owner's comments not later than 2 (two) Months before the
expected first major shipment. If any change shall become necessary for the
shipping schedule, the Contractor shall notify the Owner the revised shipping
schedule without delay.
20.4 The Contractor shall select qualified and reliable shipping companies or forwarding
companies and advise the Owner not later than 3 (three) Months before any
Materials are ready for shipment. The Contractor shall seek the Owner's agreement
within 1 (one) Month upon submission of list of shipping companies or forwarding
companies.
20.5 The Contractor shall in time secure the shipping space for the Materials and not less
than 7 (seven) Working Days before shipment give the Owner preliminary shipping
notice including vessel name and estimated time of departure and arrival together
with 3 (three) sets of preliminary packing lists.
20.6 Within 3 (three) Working Days after shipment, the Contractor shall by facsimile give
the Owner final shipping notice, including vessel name, time of departure and
estimated time of arrival and volume.
20.7 The date of bill of lading of loading port shall be taken as the actual shipping date.
20.8 If any Material is missing and/or damaged during transportation, the Contractor shall
supply such item as quickly as possible and if necessary and practicable by air
freight, then the cost shall be returned to the Contactor by insurance, so that the
Contract period will not be affected by such delay.
20.9 Any taxes and import duties imposed on such replacements, if any, shall be borne by
the Contractor if the Owner has already paid such taxes or import duties for the
missing material or if the Owner has originally obtained exemption of such taxes or
import duties for the missing material.
24. Contract _________
Page 24 of 44
Owner Contractor
20.10 If the Contractor or any Vendor is required to obtain approval or permit from any
governmental authority for exporting special equipment and material, the Contractor
shall inform the Owner of such requirement upon the delivery of final shipping
schedule.
20.11 If import of any of Materials is controlled by Indonesian Government, the Owner may
request the Contractor to submit documents (e.g. certificate of analysis,
specification, catalog and technical data) prepared by the manufacturer of such
items but not later than 2 (two) Months prior to shipment. The Contractor shall use its
best efforts to obtain such documents from the relevant manufacturer(s) and deliver
them to the Owner as soon as practicable, however not later than 3 (three) weeks
prior to the arrival of the shipment. In the case of radioactive products, the above
documents shall be delivered to the Owner not later 2 (two) Months prior to the
arrival of the shipment.
20.12 The Contractor shall undertake to ship Materials and/or any parts thereof under deck
unless impractical due to oversize or overweight. In case of unavailability of space
under deck for any particular shipment, both Parties shall consult with each other to
agree on other appropriate arrangement.
20.13 Container shall be allowed to be shipped on deck.
20.14 Transhipment (changing of ship) shall not be allowed, if the transport is not made by
containers.
20.15 The Contractor agrees that each shipment of the Materials under Contract shall
include spare parts thereof.
21. PROGRESS
The Contractor shall give the Owner full information in advance as to its plans for
performing each part of its Work and its performance of the Work being done. If the
Contractor’s actual progress is inadequate to meet the requirements of the
Contract, the Owner may so notify the Contractor who shall thereupon take such
steps as may be necessary to improve its progress. Progress report should be on
monthly basis.
22. TESTING
22.1 Unless otherwise provided in the Contract, testing of Materials and spare parts shall
be performed by the Contractor at its expense and in accordance with the Contract
requirements so as to facilitate sound and complete fulfillment of the Work. At the
25. Contract _________
Page 25 of 44
Owner Contractor
completion of the final ex-work quality inspection and testing, the Contractor shall
issue the Quality Test Certificate for the relevant equipment.
22.2 The Owner at its cost may attend witness such tests upon written notice to the
Contractor. The Contractor shall inform the Owner of schedule, if any, of testing of
Materials.
23. INSPECTION
23.1 The Contractor shall request Vendors and/or Subcontractors to allow the Owner or
its authorized representative to access their premises at all reasonable times for
inspection and expediting purposes with respect to the condition and progress of
manufacture, production or testing of the Materials.
23.2 The Contractor shall assist the Owner or its representative to obtain the permission
and entry visas for visiting the shop of the Contractor and Vendors.
23.3 The Contractor shall provide sufficient, safe, and proper facilities at all times for such
inspection and expediting of Materials, and shall furnish full information concerning all
material entering into Materials and grant the Owner and the Owner's Representative
free access at all reasonable times to the shops where Materials are manufactured,
stored, or assembled.
23.4 All traveling and personal expenses incurred by the Owner or the Owner's
Representative for visiting the shops as above shall be borne by the Owner.
23.5 At least 14 (fourteen) Day(s) before the Contractor starts testing the Materials or
parts thereof in the Contractor's shops or in those of Vendor and/or Subcontractor,
the Contractor shall inform the Owner in writing accordingly, indicating the item
concerned, the location of the shop and the schedule of testing.
23.6 The Owner shall, at all reasonable times, be entitled to ascertain the state and
progress of manufacture. Visits to the Contractor's manufacturing locations shall be
during working hours.
23.7 The Contractor shall, during the visit of the Owner and/or the Owner's
Representative, provide the Owner with all documents and data as are necessary to
judge the state of the Materials and the progress thereof.
23.8 During the inspection of items under manufacture, the visitor(s) shall be attended by
the shop superintendent in charge or on deputy, who shall give the visitor(s) all
requested information related to the manufacture of the Materials.
26. Contract _________
Page 26 of 44
Owner Contractor
23.9 The Owner shall be entitled to visit, in addition to the shops, the offices, which are in
charge of the work to be performed in connection with the Contract.
23.10 The Contractor shall be informed of a visit to the respective Vendors and/or
Subcontractors in advance at least 7 Day(s) prior to the visit date.
23.11 It shall be the responsibility of the Contractor to inspect Materials prior to delivery.
The making or failure to make by the Owner of any inspection of, or acceptance of
Materials, shall in no way impair the Owner's right to reject non conforming Materials
or release or discharge the Contractor from any of his obligations.
23.12 The Contractor shall, upon receipt of request from the Owner, provide the Owner
with information relating to the manufacture, production or testing of Materials.
23.13 Based on the agreed inspection and test program, the Owner has the right to
witness inspection activities during the Construction and co-sign on inspection
reports.
24. HEALTH, SAFETY, SECURITY AND ENVIRONMENT
The terms and conditions in accordance with Health, Safety, Security and
Environment for the performance of Works by the Contractor shall be refer to
Appendix “C”.
25. STANDARDS AND CODES
Wherever references are made in the Contract to standards or codes in accordance
with which Work is to be performed, the edition or revision of the standards or codes
current on the Effective Date shall apply unless otherwise expressly stated. Lists of
standards and codes shall be referred to Appendix “A”.
26. COOPERATION WITH OTHERS
The Owner, the Contractor, and the Subcontractors may be working at the Site
during the performance of the Contract and the Work or use of certain facilities may
be interfered with as a result of such concurrent activities. The Owner and the
Contractor shall mutually agree to re-schedule if necessary the order of performance
of the Work in such a manner as will minimize interference with the work of any other
Party. The Owner shall use its best effort to minimize the interruption of the Work by
the Subcontractors.
27. Contract _________
Page 27 of 44
Owner Contractor
27. RESPONSIBILITY FOR WORK AND PROPERTY
27.1 Work in Progress, Materials, and Construction Equipment
The Contractor shall be responsible for and shall bear any and all risk of loss or
damage to work in progress, Work, Materials, Construction Equipment supplied and
delivered by the Contractor to the Site until the date of issuance of SKPP and PAC.
27.2 Delivery, Unloading and Storage
Responsibility for the performance of the Contract shall be as follows or otherwise
expressly stated.
(a) Receiving all Off-Shore Materials at the point of import and handling any
formalities for customs clearance (by the Owner);
(b) Maintaining complete and accurate records of all Materials and Construction
Equipment received, stored and issued for use in the performance of the
Contract by the Owner and the Contractor jointly;
(c) Receiving and unloading at the Site by the Contractor;
(d) Storing in a secure and proper storage of materials subject to degradation in
weather tight enclosures (by the Contractor);
(e) Delivering from storage to the Site all Materials and the Construction
Equipment as required by the Contractor.
27.3 Property
The Contractor shall plan and conduct its operations so as not to:
(a) Enter upon lands in their natural state unless authorized by the Owner;
(b) Damage, close or obstruct any utility installation, highway, road or other
property unless/until permits therefore have been obtained;
(c) Disrupt or otherwise interfere with the operation of any pipeline, telephone,
electric transmission line, ditch or structure unless otherwise specifically
authorized;
(d) Damage or destroy cultivated and planted areas, and vegetation such as trees,
plants, shrubs, and grass on or adjacent to the premises unless, as
28. Contract _________
Page 28 of 44
Owner Contractor
determined by the Owner, do interfere with the performance of the Work
through operation of equipment.
The Contractor shall be entitled to compensate on its account due to the
Contractor’s failure to protect all materials, equipment and environment as described
herein. All costs in connection with any repairs or restoration necessary or required
by reason of unauthorized obstruction, damage or use shall be borne by the
Contractor.
28. LIABILITY FOR ACCIDENTS AND DAMAGE
28.1 Damage to persons and property before the issuance date of Performance
Acceptance Certificate.
The Contractor shall, indemnify the Owner in respect of death or injury to any person
and of all damages to any property occurring from the performance of the work by
the Contractor until the issuance of PAC and against all actions, suits, claims,
demands, costs, charges and expenses arising in connection therewith that shall be
occasioned attributable to the Contractor or by defective design (other than a design
made, furnished or specified by the Owner and for which the Contractor has
disclaimed responsibility in Writing within a reasonable time after the receipt of the
Owner instructions), materials or workmanship.
28.2 Damage to persons and property during the Warranty Period.
28.2.1 The Owner shall be responsible and liable for any negligence.
28.2.2 If there shall occur any loss of or damage or injury to any property or person
attributable to the Contractor, the Contractor shall be liable as follows:
(a) In respect of loss of or damage to the said section or portion, the
Contractor’s obligations shall be as defined in Article 28.1 of this
Contract.
(b) In respect of damage or injury to any other property or to any person
and of any actions, claims, demands, costs, charges and expenses
arising in connection therewith the Contractor shall be liable to the
extent that such damage or injury was attributable to the Contractor by
defective materials or workmanship used or while on the Site.
28.3 Claims for damage to person or property
In the event of any claim being made against the non-responsible Party arising out of
the matters referred to in and in respect of which the responsible Party may be liable
29. Contract _________
Page 29 of 44
Owner Contractor
under this Article, the responsible Party shall be promptly notified thereof, and may at
his own expense conduct all negotiations for the settlement of the same and any
litigation that may arise there from. The non-responsible Party shall not, unless and
until the responsible Party shall have failed to take over the conduct of the
negotiations or litigation, make any admission which might be prejudicial thereto. The
non-responsible Party shall, at the request of the responsible Party afford all available
assistance for any such purpose and shall be repaid all reasonable costs incurred in
so doing.
28.4 Accident or injury to workmen
The responsible Party shall indemnify the non-responsible Party against all actions,
suits, claims, demands, costs or expenses arising in connection with death or
injuries (other than such as may be the responsibility of the non-responsible Party,
his agents or servants) suffered by persons employed by the responsible Party or his
Subcontractor, whether at law or under any statutes dealing with the question of the
liability of employers for injuries suffered by employees.
29. TRAINING
29.1 The Parties agree that the Contractor will provide training program for the Owners
employees as further detailed in Appendix D.
30. CLEANING UP
30.1 The Contractor shall keep the areas in which Work is being performed inclean and
safe condition. Upon completion of any portion of its Work, the Contractor shall
promptly remove from the Work area all its Construction Equipment, temporary
structures except as specifically agreed and surplus materials not to be used at or
near the same location during later stages of Work. Upon completion of the Work,
the Owner shall at its expense satisfactorily dispose of all rubbish, scrap and waste
material as per local regulation.
30.2 The Contractor shall return to the Owner’s warehouse or jobsite storage area all
salvageable the Owner-supplied materials and shall restore the Site where
appropriate to its original condition except where specifically agreed to the contrary.
The Contractor shall leave the premises inclean and safe condition.
31. SECURITY GUARDS AND LIGHTING
30. Contract _________
Page 30 of 44
Owner Contractor
The Contractor shall maintain at its own expense all lighting, fencing and security
guards when and where necessary for the proper and safe execution and the
protection of the Work until the date of Performance Acceptance Certificate. The
Contractor shall, at its expense, provide artificial light sufficient to permit Work to be
carried on efficiently, satisfactorily and safely, and to permit through inspection when
any Work is performed at night or where daylight is obscured until the date same as
above. During such time periods the access to the place of the Work shall also be
clearly illuminated.
32. MECHANICAL COMPLETION
32.1 As soon as all the units have been completed mechanically and structurally
excluding such minor items as finishing of insulation and painting, and other items
not affecting the operation or safety of the unit, the Contractor shall arrange Pre-
commissioning as soon as possible until the issuance of SKPP.
32.2 The erection of the Plant is completed if the provisions of the check list for Plant
completion have been reached. Some minor amount of work, such as finishing the
insulation or painting, removal of temporary erection facilities, or general clean up,
still to be done by the Contractor or some deficiency not affecting the Plant operation
require correction shall not be regarded as uncompleted erection.
32.3 Within 2 (two) Day(s) after the specified checks have been successfully performed,
protocols of Mechanical Completion for the respective units, interconnecting piping
and cables shall be signed by the representative of both Parties at the Site.
33. PRE-COMMISSIONING AND THE COMMISSIONING
33.1 As soon as all the units have been completed mechanically as stipulated in Article 32
of this Contract, the Contractor shall perform the Pre-commissioning as soon as
possible.
33.2 As soon as the Plant or any units of the Plant thereof is substantially complete, it
shall be inspected by the Owner and the Contractor before any tests are carried out.
33.3 When all the items of equipment and materials of the Plant are ready and have been
completed pursuant to this Contract, the Parties shall review the procedures for the
pre-agreed tests for the demonstration of the completion of Construction of the units
of the Plant, to be undertaken in accordance with this Contract and detailed
procedures therewith.
31. Contract _________
Page 31 of 44
Owner Contractor
33.4 After completion of Construction for a unit, Pre-commissioning for this unit can be
started by unit.
33.5 During Pre-commissioning, detailed procedures of Commissioning such as
instrument calibration, items of recording, sampling methods and analyzing methods
which are necessary for Commissioning shall be submitted by the Contractor.
33.6 During Pre-commissioning and Commissioning, the Owner shall prepare the
personnel for operation, maintenance and testing as well as all raw materials and
utilities in the required quantity and quality.
33.7 Upon completion of the Pre-commissioning procedure, the Contractor will proceed
with the Commissioning procedure and both Parties shall agree on the date of the
Commissioning and the Contractor shall perform the Commissioning under the
Owner’s support within 5 (five) Day(s) from the date of such agreement.
33.8 The Commissioning shall be carried out in accordance with the instruction of the
Contractor’s technical personnel on the Site.
33.9 The results and the evaluations of each Commissioning shall be recorded in a
protocol and signed by the representatives of both Parties within 2 (two) Day(s) after
the completion of such Commissioning. In the event a Commissioning is not
successfully carried out due to the Contractor’s fault, the Contractor shall make
necessary modifications to the equipment and materials or design or the instruction
of operation of the Plant as soon as possible. After making the modifications, the
Commissioning shall be carried out again in accordance with Article 33. If it is
necessary to have any of the above-mentioned modifications carried out at the Site,
the Owner shall make its best endeavours to give its assistance when requested by
the Contractor. However, the direct cost of performing modifications or corrections
including but not limited to all labor and materials shall be borne by the Contractor.
33.10 Any equipment or materials destroyed or damaged due to the Contractor’s fault and
which are within the scope of the Contractor’s Work shall be delivered by the the
Contractor, if necessary and practical CIF (in accordance with Incoterms 2000)
airport of Indonesia. The delivery shall be performed as quickly as possible. Should it
be necessary to send back to the country of origin any equipment for repair or
replacement, all transport cost and cost of repairing or replacement shall be borne
by the Contractor.
33.11 The replaced or repaired equipment shall be delivered by the Contractor on its own
costs including import duties, the cost for transportation to the Site, etc., (if any).
34. ACCEPTANCE
32. Contract _________
Page 32 of 44
Owner Contractor
34.1 If all the guarantee figures of the Plant are fulfilled in all Commissioning as specified
in Article 33, Performance Acceptance Certificate of the Plant shall be signed in 4
(four) copies, 2 (two) copies for each Party, by the representatives of both Parties
within 2 (two) Day(s) after the guarantee figures are fulfilled (“Performance
Acceptance Certificate“). The Performance Acceptance Certificate of the Plant
stipulated in this Article shall not release the Contractor from its liability for Materials
during the Warranty Period. The Contractor shall submit to the Owner list of
outstanding items to be performed by the Contractor under the Contract. Such list
shall be subject to the Owner's approval.
34.2 If the guarantee figures are not fulfilled partly or completely during the
Commissioning, both Parties shall jointly make investigations to find out the reason
to clarify the responsibility and to settle it as follows:
34.2.1 If due to the Contractor’s fault, the guarantee figures are not fulfilled within 21
(twenty one) Months of working period pursuant to Article 13.2 of this
Contract, the Owner shall agree to have an extension of the Commissioning
period to make corrections and to have further Commissioning. Should the
Commissioning still fail continously, the Parties agree that the Contractor
proceed additional Commissioning and after the achievement of the
guarantee figures, the Contractor shall pay to the Owner the liquidates
damages in accordance with Article 36.2 of this Contract, and the Owner
shall issue to the Contractor the Performance Acceptance Certificate.
34.2.2 If the non-fulfillment of the guarantee figures is due to the Owner’s fault (such
as lack of LPG, utilities and of other items which are in the Owner’s
responsibility according to the conditions of the Contract), the Commissioning
periods as per Articles 33.7 and/or this Article shall be extended by the
periods of delay due to the Owner’s fault up to a maximum of 6 (six) Months
from the Mechanical Completion. During these periods of delay all the
expense for the Contractor and an interest based on the interest rate
applicable in PT Bank BNI (Persero), Tbk at the then applicable time, shall be
for the Owner’s account. The number of the Contractor’s personnel shall be
discussed and fixed by both Parties.
34.2.3. In case the Commissioning has not been completed within 27 (twenty seven)
Months from start of the work by the Contractor for any reasons attributable to
the Owner, the Plant shall be deemed to be accepted and the Owner shall
issue to the Contractor the Taking-over Certificate of the Plant. The Warranty
Period shall in no event valid beyond 6 (six) Months from the date of the
Taking-over Certificate.
In the event the Plant shall be deemed to be accepted as mentioned above,
the Owner shall pay to the Contractor the remaining 15% (fifteen percent)
within 10 (ten) Working Day(s) from such acceptance.
33. Contract _________
Page 33 of 44
Owner Contractor
35. CONFIDENTIALITY
35.1 Each Party shall take due measures to keep confidential the information
communicated to it from the other Party including the Drawings, technical
requisitions, specifications and other project documents provided by either Party
during the performance of the Contract.
35.2 The obligation of each Party under this Article, however, shall not apply to that
information which:
(a) now or hereinafter enters the public domain through no fault of the other Party;
(b) can be proved to have been in the possession of the other Party at the time of
disclosure and which was not previously obtained, directly or indirectly, from
such Party; or
(c) otherwise lawfully becomes available to the other Party from a third party under
no obligation of confidentiality.
35.3 This Article shall survive after the termination of the Contract.
36. GUARANTEES AND LIQUIDATED DAMAGES
36.1 The Contractor guarantees that the Plant shall possess the modern technology
among the relevant plants of the Contractor at the date of the Contract, that the
Materials are of high quality and that their type selection complies with the
requirements of process technology, operation and long-term service. The
Contractor shall supply the engineering drawings and other documents completely
and correctly in order to carry out successfully the Commissioning as well as normal
and safe operation and maintenance of the Plant.
36.2 If the Contractor fails to achieve the Performance Guarantee Figures within 21
(twenty one) Months of working period pursuant to Article 13.2 of this Contract due to
Contractor’s faults, then the Contractor shall pay to the Owner the liquidated
damages in the amount of 0.1% (zero point one percent) of the Contract Price for
each Day(s) of delay starting from the first Day(s) of the 22nd (twenty second)
Month. Such liquidated damages, in total, shall in no case exceed 5% (five percent)
of the Contract Price.
36.3 The Contractor guarantees that the Plant can reach the guarantee figures as stated
in Appendix “A” – Quality, Quantity and Procedures for Commissioning provided that
34. Contract _________
Page 34 of 44
Owner Contractor
the Plant is operated under normal conditions by the Owner. The Contractor shall
prove that the guaranteed figures can be reached in the Commissioning according to
Article 33. In case of deviations from guaranteed figures due to the Contractor’s
fault, the Contractor shall be responsible and bear all costs and expenses to achieve
the guaranteed figures.
36.4 The payment of liquidated damages for performance guarantee shall constitute
complete satisfaction of the Commissioning and any other claims or actions that
may arise in connection with said guarantees, and the Commissioning will be
considered by the Parties as having been satisfactorily completed in all respects.
However, the liquidated damages under this clause 36, in total, shall in no case
exceed 5% (five percent) of the Contract Price.
The Owner is entitled to obtain the payment for the liquidated damages mentioned
above from the call or withdrawal of the Performance Bond in the maximum amount
of 5% of the Contract Price.
36.5 In case any defect of Works is found during erection, mechanical tests,
Commissioning the defect shall be checked by both Parties and if such defect is due
to the Contractor's fault, the Contractor shall correct, repair or replace the Work at its
own expenses. If the Contractor is responsible for removing or correcting the
defects, the Owner shall supply the Contractor, if requested by the Contractor, the
necessary personnel, cranes, etc. for performing the removal of the defects. The
cost thus incurred shall be borne by the Contractor. The removal of defects shall be
performed as quickly as possible and the Contractor shall do its best to ensure that
the progress of the Work is not adversely affected.
36.6. Each of the Parties hereby represents and warrants that each Party is duly
organized and validly existing under the laws of the Republic of Indonesia and has
the power and authority to enter into this Contract and to carry out and perform the
terms and conditions of this Contract.
36.7. Each Party has taken any and all necessary actions and necessary approvals,
authorizations and formalities required to be obtained in order to enable each Party
to lawfully enter into and perform its obligations under this Contract and to ensure
that such obligations expressed to be assumed by it hereunder are legal, valid,
binding and enforceable and have been done, fulfilled or performed.
37. WARRANTIES
37.1 The Contractor shall fully perform and complete the Work under the Contract in a
good and workmanlike manner as defined in the Contract.
35. Contract _________
Page 35 of 44
Owner Contractor
37.2 All Work performed and Materials installed by the Contractor are warranted to
conform to the design, drawings, documents, plans, specifications, codes,
regulations and standard industry practices as set forth in the Contract and shall be
at least those which can reasonably be expected from an experienced leading the
Contractor performing similar work under similar conditions, of sufficient size and
capacity and of first class quality so as to fulfill in all respects all operating conditions
specified in the Contract and free from any defect due to faulty design, defective
materials and/or faulty workmanship. If any defect of the Work attributable to the
Contractor is found at any time up to 12 (twelve) Months from the date of
Performance Acceptance Certificate and the Contractor is notified of such defect,
the Contractor shall, at its own expense and as promptly as possible, repair, replace
or remedy such defect as may be necessary to permit the Work to conform to the
applicable drawings, documents, plans, specifications, codes, regulation and
standard industry practices.
37.3 The Warranty Period for the replaced or repaired parts for reasons attributable to the
Contractor shall be further extended for that effect by 12 (twelve) Months from the
date of such repair or replacement. However, this extended Warranty Period shall
not in no case be longer than 24 (twenty four) Months after the date of Performance
Acceptance Certificate. The amount of the Warranty Bond must be maintained
through the extended Warranty Period pursuant to Article 17.3.
37.4 The Owner shall notify the Contractor in writing the nature of any defect, which
occurs within the Warranty Period, however, such notification shall be made at the
latest within 30 (thirty) Day(s) after expiration of the Warranty Period.
37.5 The Contractor, if the Owner is authorized by the Contractor, shall reimburse the
Owner the cost pertaining to such repair and/or services. Customs clearance and
transport within Indonesia in connection with defective or replaced equipment or
materials shall be arranged by the Owner at cost of the Contractor, also any
applicable taxes in Indonesia in connection therewith shall be paid by the Contractor.
37.6 Any and all costs and expenses incurred by the Contractor in making good and
correcting any defect, except for defects attributable to the Owner, in accordance with
this Article shall be borne by the Contractor including but not limited to the cost for
repair and replacement of items of Materials, customs duties, taxes and port charge,
transportation of materials from or to the Site, dismantling and removal from the Site
and export of any defective item of Materials, construction, erection, testing and any
cost or expense for modification or repetition of design, engineering, etc.
37.7 In the event the Contractor fails to start to remedy any defect, except for defects
attributable to the Owner, within 14 (fourteen) Day(s) after the receipt of the Owner’s
written notice, describing defect in accordance with Article 37, the Owner shall be
entitled to claim under the Warranty Bond to the extent of the cost of undertaking the
necessary remedial service itself. Such notice shall identify the nature of and the
36. Contract _________
Page 36 of 44
Owner Contractor
date on which the Contractor was given notice of the defect, and shall include
statements that (i) the Contractor has not remedied the defect(s), and (ii) the Owner
desires to remedy such defect(s).
37.8 The defective parts shall be returned by the Owner to the Contractor at the request
of the Contractor at the Contractor's cost. The request shall be made within 14
(fourteen) Day(s) after replacement or renewal, and the parts shall be returned as
soon as possible after the request.
37.9 In case of willful misconduct or gross negligence by the Contractor, the provisions of
Article 37 shall be the sole remedy available to the Owner under the Contract for
rectification of defects in the Work.
37.10 The Contractor's response to defects or guarantee service calls under this Article
shall be such that upon notification by the Owner that repair of defects or service
work is required, the Contractor shall:
(a) Respond immediately to faximile, telephone or e-mail notification.
(b) Dispatch engineers or other personnel to Site within the shortest possible
time, if requested by the Owner.
37.11 Under the warranties of Article 37, the Contractor shall not be responsible for the
defects and/or damages due to i) improper operation or maintenance of the Plant by
the Owner, ii) normal wear and tear, or iii) any design, specifications or other data
designated, supplied or specified by or on behalf of the Owner.
38. PATENT INDEMNITY
38.1 The Contractor shall indemnify the Owner from and against any and all direct
damages, claims, demands, losses, costs and expenses the Owner may suffer as a
result of any infringement or alleged infringement of any patent, registered design,
trademark, copyright other intellectual property right registered or otherwise existing
at the signing date of the Contract by reasons of the use of the Supply and/or
Materials, but the Owner shall not settle any claim or demand from a third party
without taking procedures as per Article 38.2.
38.2 If any proceedings are brought forward or any claim is made against the Owner
arising out of the matters referred to in Article 38.1 above, the Owner shall promptly
give the Contractor written notice thereof and the Contractor may at its own expense
and in the Owner’s name conduct such proceedings or claim and any negotiations
such as either make available the Owner the rights in question or at the Contractor’s
discretion alter the Supply at the Contractor’s cost.
37. Contract _________
Page 37 of 44
Owner Contractor
38.3 If the Contractor fails to notify the Owner within 15 (fifteen) Day(s) after receipt of
such notice that it intends to conduct any such proceedings or claims, then the
Owner shall be free to conduct the same on its own behalf. Unless the Contractor
has so failed to notify the Contractor within 15 (fifteen) Day(s) period the Owner shall
not make any admission which may be prejudicial to the defense of any such
proceedings or claim.
38.4 The Owner shall, at the Contractor’s request, afford all available assistance to the
Contractor in conducting such proceedings or claim, and the Owners shall be
reimbursed by the Contractor for all reasonable expenses incurred in so doing.
39. LIABILITY OF THE PARTIES
39.1 The maximum aggregate liquidated damages of the Contractor to the Owner arising
under the Contract in respect of liquidated damages under Articles 36.2 and 36.4
shall in no case exceed 5% (five percent) of the Contract Price.
39.2 Neither Party shall be liable to the other Party for any consequential damage or
losses including loss of production or loss of profits.
40. TRANSFER OF THE OWNERSHIP
The ownership of the Plant will be transfer upon the Parties sign the minutes of
transfer of ownership. For the avoidance of doubt the signing of the minutes of
transfer of ownership will be made at the same date with the issuance of the PAC.
41. CARE OF WORK
41.1 The Contractor shall be responsible for the care and custody of the Work and the
Materials or any part thereof until the date of Performance Acceptance Certificate of
the Plant pursuant to Article 34 hereof.
41.2 The Contractor shall also be responsible for any loss of or damage to the Work
caused by the Contractor in the course of any work carried out pursuant to Article 37
hereof.
42. INSURANCE
38. Contract _________
Page 38 of 44
Owner Contractor
42.1 The insurance to be taken out and maintained by the Contractor with reputable
insurance companies shall be as specified below. 1 (one) copy of the relevant
policies shall be promptly passed to the Owner. The insurance should cover the
value of Contract Price.
42.2 The Contractor shall maintain the insurance policies, described below, in full force
and effect from the commencement of Work hereunder up to the date of
Performance Acceptance Certificate of the Plant. As required by the Owner, the
Owner will be named as beneficiary or co-beneficiary in respect of claims hereunder.
42.3 If the Contractor fails to take out and/or maintain in effect the insurance referred to
above, the Owner may take out and maintain in effect such insurances and may
deduct any amount due to the Contract under any premium which the Owner shall
have paid to the insurance companies.
42.4 The Contractor shall promptly advise the Owner of any and all claims lodged under
the insurance policies, and the status of any outstanding or unpaid claims in respect
thereof.
42.5 The Contractor (or Subcontractors) shall maintain the following insurance policies
with the Owner as a co-insured:
(a) Erection All Risks Insurance
(b) Third Party Liability Insurance
(c) Employee social security (Jaminan Sosial Tenaga Kerja) for the employee of
the Contractor only
43. FORCE MAJEURE
43.1 Neither Party shall be considered in default of performance of its obligation under
the Contract to the extent that the performance of such obligation is delayed or
prevented by force majeure.
43.2 Force majeure is herein defined to be acts of God, acts of war (declared or
undeclared), acts of government, embargo, hostilities, riots, earthquake, flood, civil
unrest, insurrection, strikes or lockouts, etc. which are beyond reasonable control of
both Parties and unforeseeable as of the signing date of the Contract.
43.3 Either Party shall give notice in writing to the other of the occurrence of Force
Majeure as soon as possible after its occurrence including its estimated duration (if
possible) and shall determine a mutually agreeable course of action. Neither the
39. Contract _________
Page 39 of 44
Owner Contractor
Owner nor the Contractor shall be subject to any liability whatsoever for any delay or
loss caused by Force Majeure.
43.4 As soon as Force Majeure is terminated the respective Party shall give immediate
written notice to the other Party. At that time the Parties shall mutually agree on the
further course of action.
43.5 Defects or damages in Materials due to failure to perform in accordance with or
breach of the Contract or negligent acts or omissions by the Contractor's Vendor or
shipping company hired by the Contractor or other persons under the Contractor's
responsibility or their representatives, shall not constitute force majeure.
43.6 Interruption of obligations under the Contract due to force majeure shall not be
considered a waiver of either Party's such obligations. If an event of force majeure
prevents either Party from carrying out its obligations under or in connection with the
Contract, such Party shall promptly notify in writing the other Party.
43.7 Each Party, upon giving written notice as above, may suspend its obligation to the
extent necessitated by the occurrence of force majeure, and relevant periods shall
be extended commensurate with such suspension. Nothing hereby shall alter any
obligation with respect to portions of Work not affected by such force majeure.
43.8 The occurrence of force majeure shall not entitle either Party to any additional
compensation whatsoever unless otherwise agreed between both Parties.
43.9 If after 180 (one hundred eighty) Day(s) from the date of giving the aforesaid notice,
the notifying Party shall still be so prevented for reasons of force majeure form
performing its obligations under the Contract, both Parties shall consult with each
other in good faith with a view to determining equitable action appropriate under such
circumstances and also termination should be taken into reasonable consideration.
43.10 Notwithstanding the period specified under the preceding paragraph, it is hereby
mutually agreed that at any time subsequent to the occurrence of force majeure,
either Party may, upon its request, discuss amicably with the other Party in order to
set the provisional arrangements to be adopted by both Parties for the purpose of
minimizing or avoiding any losses, damages or expenses which the affected Party
may incur in consequence of the suspension as provided hereunder.
43.11 The above mentioned Article 43.1 through 43.6 shall be in effect until the date of
Performance Acceptance Certificate.
44. ASSIGNMENTS AND SUBCONTRACTS
40. Contract _________
Page 40 of 44
Owner Contractor
44.1 The Contractor shall not subcontract with any third party for the performance of all or
any portion of the Work without the prior written approval of the Owner unless
otherwise stated, provided however that such approval shall not unreasonably
withheld by the Owner. Subcontracts must include provisions to secure all rights and
remedies of the Owner provided under the Contract, and must impose upon the
Subcontractor all of the general duties and obligations required to fulfill this Contract.
44.2 No assignment or subcontract approved would relieve the Contractor of its
responsibilities under the Contract.
45. VARIATION ORDER
45.1 The Owner may, at any time, in writing, request the Contractor to make variation in
the Work to be performed by the Contractor under the Contract.
45.2 In the event the Contractor deems it necessary for the execution of the Work or
deems it appropriate taking into account of then prevailing circumstances, the
Contractor may also submit to the Owner a variation proposal without receiving the
Owner's request for a variation.
45.3 Upon receipt of the Owner's written request for a variation in Work, the Contractor
shall prepare a variation proposal and furnish the same to the Owner within a
reasonable period of time but normally within 14 (fourteen) Day(s) following receipt of
such request. Each variation proposal shall be in writing and be accompanied with
information including the effect upon the Contractor's guarantees, and/or upon any
other undertakings by the Contractor hereunder.
45.4 In spite of the Owner's request for a variation as stipulated in Article 45.1, the
Contractor shall not be obligated to effect such variation which may, in the written
opinion of the Contractor to the Owner, have an adverse effect upon the Contractor's
guarantees or which will not be technically feasible.
45.5 Within 14 (fourteen) Day(s) from receipt of a variation proposal as specified in Article
45.2, the Owner shall inform the Contractor in writing of whether the Owner desires
to proceed with the relevant variation in Work. If the Contractor does not receive any
written notice from the Owner within the said 14 (fourteen) Day(s), such request for
a variation in Work shall be deemed to have been canceled by the Owner. In case of
cancellation, the Contractor shall not be reimbursed for the cost of making the
proposal. The Contractor shall not be responsible to the Owner for any claims by the
Owner arising from such cancellation.
45.6 If the Owner and the Contractor agree to effect on the Contract provisions based on
all information contained in a variation proposal, the Owner shall notify or thereof by
way of issuance of a written variation order (“Variation Order”) incorporating the
41. Contract _________
Page 41 of 44
Owner Contractor
variation in question and providing for any such necessary amendment to the
Contract as agreed between the Owner and the Contractor resulting from the effect
of such variation in every respect. The Contractor shall not be required to proceed
with any variation in Work before its receipt of the Owner's written Variation Order.
45.7 If, during the execution of Work, the Contract Price and the Project Schedule are
affected by the Owner's failure or delay in performing its obligations, or due to the
Variation Order from the Owner, the Contract Price and the Project Schedule shall
be reasonably adjusted by mutual agreement.
46. SUSPENSION
46.1 The Owner may for essential reason not deriving from the Contractor’s fault or
breach of the Contract suspend the Contract for a total aggregate period of 45 (forty
five) Day(s).
46.2 Within 14 (fourteen) Day(s) prior to each expected suspension, the Owner shall, if
possible, inform the Contractor of the reason and period of the suspension and both
Parties shall make a friendly mutual settlement during such 14 (fourteen) Day(s)
regarding the additional cost for the Contractor, the Project Schedule and other
effects of the suspension for the Contract. Should the total aggregated period of
suspension for the Contract exceed 45 (forty five) Day(s), the Owner shall pay all
additional costs and expenses to the Contractor and the Owner shall submit a
Variation Order as per Article 45 and the time for completion shall be extended
relevantly.
46.3 The Contractor may by notice to the Owner suspend performance of all or any of
its obligations under the Contract in case that the Owner fails to pay any sum due
under the Contract within 14 (fourteen) Working Day(s) from the due date of
payment.
47. TERMINATION
47.1 Termination for the Contractor’s default
47.1.1 Notwithstanding any other provisions of the Contract, the Contractor shall be
considered by the Owner in default of its contractual obligation under the
Contract if it:
(a) Substantially fails to make delivery or substantially fails to perform
Work within the time specified on Appendix “A”;
42. Contract _________
Page 42 of 44
Owner Contractor
(b) Substantially fails to perform in accordance with provisions of the
Contract or so substantially fails to make progress as to endanger
performance of the Contract in accordance with its terms;
(c)
47.1.2 Upon the occurrence of any of the foregoing, the Owner may notify the
Contractor in writing of the nature of the failure, and the Parties shall discuss
this matter and shall agree on a new delivery or progress schedule.
47.1.3 If the Contractor still substantially fails to comply with such schedule, the
Owner may terminate the whole or part of the Contract upon giving the
Contractor 14 (fourteen) Day(s) prior written notice.
47.1.4 Upon such a termination by the Owner, the Contractor shall either
immediately or upon such date as is specified in the notice of termination:
(a) cease all further work; and
(b) terminate all sub-contracts, except those to be assigned to the Owner
pursuant to item (d); and
(c) deliver to the Owner the parts of the Work executed by the Contractor
up to the date of termination; and
(d) to the extent legally possible assign to the Owner all right, title and
benefit of the Contractor to the Work and in the Materials as at the date
of termination, and, as may be required by the Contractor, in any sub-
contracts concluded between the Contractor and the Owner deliver to
the Owner all drawings, specifications and other documents prepared
by the Contractor or its Subcontractors as at the date of termination in
connection with the Works.
(e) The Owner may enter upon the Site and may complete the Work
employing any third party. The Owner may take over and use, with
payment of rental fee to the Contractor, any Construction Equipment
belong to the Contractor and which is on the Site. Upon completion of
the Work or such earlier date as the Owner thinks appropriate, the
Owner shall return to the Contractor such Construction Equipment.
47.1.5 The Contractor shall be entitled to be paid the Contract Price attributable to
the Work executed as at the date of termination.
47.2 Termination for the Owner’s default
43. Contract _________
Page 43 of 44
Owner Contractor
If the Owner fails to open the SBLC within 45 (forty five) Working Day(s) after the
date of the notification from the Owner’s bank on the readiness of the
SBLC, the Parties shall meet and discuss to proceed further step. If the Owner
fails to open the SBLC within the agreed period, then the Contractor shall be
entitled to terminate this Contract by a written notice to the Owner, and in such a
case, this Contract shall be considered terminated and Contractor will have the
rights to claim for losses, damages and expenses incurred by the Contractor and
the Owner shall pay to the Contractor such losses, damages and expenses.
47.3 Either Party may terminate the Contract immediately and without incurring thereby
any liability to the other, by merely serving a notice of termination on the other in any
of the following events:
(a) If the other Party is declared in court or notoriously becomes insolvent or
bankrupt;
(b) If a receiver is appointed to take possession of the business or assets of the
other Party and his appointment is not revoked within 15 (fifteen) Day(s).
47.4 Termination of the Contract is without prejudice to any claim for any antecedent
breach and to the right of the aggrieved Party to recover damage, loss,
compensation and all sums payable hereunder.
47.5 If after termination pursuant to this Article, it is determined for any reason that the
rights and obligations of both Parties shall be decided by arbitration in accordance
with Article 7, unless otherwise agreed by the Parties.
47.6. The Parties hereby agree to waive the provision of Article 1266 of the Indonesian Civil
Codes to the extent that the court decision or decree is required for the termination
of this Contract.
IN WITNESS WHEREOF, the Parties have caused to execute this Contract in 2 (two) original
copies on the date first written above by their duly authorized representatives.
For and on behalf of
PT. ______________________
For and on behalf of
CONSORTIUM OF [CONSORTIUM
NAME]
44. Contract _________
Page 44 of 44
Owner Contractor
Name: .............................
Title: President Director
Name: Mr. .........................
Title: