Agreement between owner and contractor

© Copyright Envision Corporation. 2002. All rights reserved. Protected by the copyright laws of the United States & Canada and by International treaties. IT IS
ILLEGAL AND STRICTLY PROHIBITED TO DISTRIBUTE, PUBLISH, OFFER FOR SALE, LICENSE OR SUBLICENSE, GIVE OR DISCLOSE TO ANY OTHER
PARTY, THIS PRODUCT IN HARD COPY OR DIGITAL FORM. ALL OFFENDERS WILL BE SUED IN A COURT OF LAW.
© Copyright Envision Corporation. 2002. All rights reserved. Protected by the copyright
laws of the United States & Canada and by international treaties. IT IS ILLEGAL AND
STRICTLY PROHIBITED TO DISTRIBUTE, PUBLISH, OFFER FOR SALE, LICENSE OR
SUBLICENSE, GIVE OR DISCLOSE TO ANY OTHER PARTY, THIS PRODUCT IN HARD
COPY OR DIGITAL FORM. ALL OFFENDERS WILL BE SUED IN A COURT OF LAW.
© Copyright Envision Corporation. 2002. All rights reserved. Protected by the copyright
laws of the United States & Canada and by international treaties. IT IS ILLEGAL AND
STRICTLY PROHIBITED TO DISTRIBUTE, PUBLISH, OFFER FOR SALE, LICENSE OR
COPY OR DIGITAL FORM. ALL OFFENDERS WILL BE SUED IN A COURT OF LAW.
© Copyright Envision Corporation. 2002. All rights reserved. Protected by the copyright laws of
the United States and Canada and by international treaties. IT IS ILLEGAL AND STRICTLY
PROHIBITED TO DISTRIBUTE, PUBLISH, OFFER FOR SALE, LICENSE OR
COPY OR DIGITAL FORM. ALL OFFENDERS WILL AUTOMATICALLY BE SUED IN A
COURT OF LAW.
AGREEMENT BETWEEN OWNER AND CONTRACTOR
This Agreement Between Owner and Contractor (the “Agreement”) effective [DATE],
BETWEEN: [OWNER NAME] (the "Owner"), a corporation organized and existing under the
laws of the [STATE/PROVINCE], with its head office located at:
AND: [CONTRACTOR NAME] (the "Contractor"), a corporation organized and existing
under the laws of the [STATE/PROVINCE], with its head office located at:
WHEREAS, Owner finds that the Contractor is qualified to perform the work, all relevant factors considered,
and that such performance will be in furtherance of Owner's business.
Agreement Between Owner and Contractor Page 1 of 4

NOW, THEREFORE, in consideration of the mutual covenants set forth herein and intending to be legally
bound, the parties hereto agree as follows:
1. MATERIAL AND LABOR PROVIDED
The Contractor agrees to provide all of the material and labor required to perform the following work for:
[DESCRIBE WORK TO BE PERFORMED]
as shown by the drawing(s) and described in the specifications prepared by [NAME] and provided by the
Owner, which are identified by the signatures of the parties to this agreement and which form a part of this
agreement.
The Contractor agrees to provide and pay for all materials, tools and equipment required for the
prosecution and timely completion of the work. Unless otherwise specified, all materials shall be new and
of good quality.
In the prosecution of the work, the Contractor shall employ a sufficient number of workers skilled in their
trades to suitably perform the work.
2. PAYMENT
The Owner hereby agrees to pay the Contractor, for the aforesaid materials and labor, the sum of
[AMOUNT], in the following manner:
[DESCRIBE METHOD AND TIMING OF PAYMENT]
3. COMPLETION OF THE WORK
The Contractor agrees that the various portions of the above-described work shall be completed on or
before the following dates:
[INSERT DATES]
and the entire above-described work shall be completed no later than the [DATE].
4. MODIFICATIONS TO THE WORK
All changes and deviations in the work ordered by the Owner must be in writing, the contract sum being
increased or decreased accordingly by the Contractor. Any claims for increases in the cost of the work
must be presented by the Contractor to the Owner in writing, and written approval of the Owner shall be
obtained by the Contractor before proceeding with the ordered change or revision.
5. ACCESS
The Owner, Owner's representative and public authorities shall at all times have access to the work.
6. CONFORMITY WITH DRAWINGS AND SPECIFICATIONS

The Contractor agrees to re-execute any work which does not conform to the drawings and specifications,
warrants the work performed, and agrees to remedy any defects resulting, from faulty materials or
workmanship which shall become evident during a period of one year after completion of the work.
7. INSURANCE COVERAGE
The Owner agrees to maintain full insurance on the above-described work during the progress of the
work, in his own name and that of the Contractor.
The Contractor agrees to obtain insurance to protect himself against claims for property damage, bodily
injury or death due to his performance of this agreement.
8. DELAYS
In the event the Contractor is delayed in the prosecution of the work by acts of God, fire, flood or any
other unavoidable casualties; or by labor strikes, late delivery of materials; or by neglect of the Owner;
the time for completion of the work shall be extended for the same period as the delay occasioned by any
of the aforementioned causes.
9. INDEMNIFICATION
In the event the work is delayed due to neglect of the Contractor, the Contractor agrees to pay the Owner
the sum of [AMOUNT] per [DAY/WEEK/MONTH] as liquidated damages until such time as the work is
completed.
10. NO ASSIGNMENT
Neither the Owner nor Contractor shall have the right to assign any rights or interest occurring under this
agreement without the written consent of the other, nor shall the Contractor assign any sums due, or to
become due, to him under the provisions of this agreement.
11. GOVERNING LAW
This agreement shall be interpreted under laws of the State of [STATE/PROVINCE].
12. ATTORNEY’S FEES
Attorney's fees and court costs shall be paid by the defendant in the event that judgment must be, and is,
obtained to enforce this agreement or any breach thereof.
IN WITNESS WHEREOF, the parties hereto have executed this Agreement as of the day and year first
above written.
OWNER CONTRACTOR

Authorized Signature Authorized Signature
Print Name and Title Print Name and Title

Agreement between owner and contractor

Recommandé

Recommandé

Contenu connexe

Tendances

Tendances (20)

Similaire à Agreement between owner and contractor

Similaire à Agreement between owner and contractor (20)

Dernier

Dernier (20)

Agreement between owner and contractor